Terms of Service | TLC Construction & Development LLC

Legal

Terms of Service

Effective Date: May 28, 2026

By accessing or using tlcconstructionwa.com, you agree to be bound by these Terms of Service. If you do not agree, please do not use this website.

Our Services

TLC Construction & Development LLC provides residential kitchen and bathroom remodeling services in Pierce and King County, Washington. All work is performed under a licensed General Contractor in the State of Washington.

  • Kitchen remodels
  • Bathroom remodels
  • Full gut rehabs and interior renovations

Age Restriction

You must be 18 years of age or older to use this website, submit your information, or enter into any agreement with TLC Construction & Development LLC.

SMS Program

By submitting your phone number and opting in through our website form, you consent to receive SMS text messages from TLC Construction & Development LLC. These messages may include:

  • Responses to your project inquiry
  • Estimate follow-ups and scheduling
  • Project updates and reminders
  • Promotional offers and announcements
  • Message frequency varies
  • Msg & data rates may apply
  • Reply STOP to opt out at any time
  • Reply HELP for support

Carrier Disclaimer: Carriers are not liable for delayed or undelivered messages. TLC Construction & Development LLC is not responsible for any charges incurred from your mobile carrier related to SMS communications.

Estimates & Contracts

All estimates provided through this website or by phone are non-binding until a written contract is signed by both parties. No work will begin until a signed agreement is in place and any required deposit has been received.

Our Guarantee

On-Time Guarantee: We complete every project on time per the signed contract. If we fail to meet the agreed completion date due to reasons within our control, you receive 5% off the total project cost.

Limitation of Liability

TLC Construction & Development LLC shall not be held liable for delays, cost overruns, or project interruptions caused by:

  • Material shortages or supply chain delays
  • Weather conditions or natural events
  • Client-requested changes after contract execution
  • Circumstances outside our reasonable control

Our total liability for any claim arising from services rendered shall not exceed the total amount paid under the applicable project contract.

Privacy Policy

Your use of this website is also governed by our Privacy Policy, which is incorporated into these Terms by reference. Please review it to understand our data practices.

Governing Law

These Terms of Service are governed by and construed in accordance with the laws of the State of Washington. Any disputes shall be resolved in the courts of Pierce County, Washington.

Contact Us

TLC Construction & Development LLC
Phone: 253-322-3462
Website: tlcconstructionwa.com